Terms and Conditions

Please read these terms & conditions carefully. These are the general terms & conditions governing your access and use of https://bolddeveloper.com/ (the “website”).

Acceptance of the terms of use

This website is owned and operated by the Bold Developer (“Bold Development company”, “Bold”, “we” or “us”). The following terms and conditions, any brochure or factsheet, sales offer (or any lease, booking form, sale and purchase agreement or any other legal, contractual or other document or resource) as well as any content made available through the website’s investor relations or Bold Developer webpages sections including but not limited to audited financials, investor presentations, green finance frameworks, and second-party opinions (together the “documents”) entered into with Bold Developer or any of its affiliates pertaining to a commercial lease, unit or plot in a Bold Developer project or any other legal or commercial arrangement in respect of which this website is used together with any documents they expressly incorporate by reference (collectively, these “terms of use”), govern your access to and use of the website, including any content, functionality and services offered on or through the website whether as a guest or a registered user. This includes access to the investor relations section of the website, which are also subject to the supplemental investor website disclaimer and the Bold Developer section.

Please read the terms of use carefully before you start to use the website. By using the website or, you accept and agree to be bound and abide by these terms of use and our privacy policy, found at https://bolddeveloper.com/, incorporated herein by reference. If you do not want to agree to these terms of use or the privacy policy, you must not access or use the website.

Changes to the terms of use

Bold Developer reserves the right to revise and update these terms of use, the privacy policy or any other content (including uploaded documents or other resources) of the website from time to time in our sole discretion and without prior notice. All changes are effective immediately when we post them and apply to all access to and use of the website thereafter.

Your continued use of the website following the posting of revised terms of use means that you accept and agree to the changes. You are expected to check this page from time to time so you are aware of any changes, as they are binding on you.

Accessing the website and account security

We reserve the right to withdraw and / or amend the website, and any service or material we provide on the website, in our sole discretion without notice. We will not be liable if for any reason all or any part of the website is unavailable at any time or for any period. From time to time, we may restrict access to some parts of the website, or the entire website, to any user, including registered users.

You are responsible for:

• Making all arrangements necessary for you to have access to the website.
• Ensuring that all persons who access the website through your internet connection are aware of these terms of use and comply with them.

To access the website or the resources it may offer including, but not limited to, access to any documents or payments using credit cards or other forms of electronic payment (if applicable), you may be asked to provide certain registration details or other information. It is a condition of your use of the website that all the information, including, without limitation, personal information (including, if applicable, credit card information or information pertaining to other forms of electronic payments), you provide on the website is correct, current and complete. You agree that all relevant information you provide to register with this website or otherwise, including but not limited to through the use of any interactive features on the website, is governed by our privacy policy, and you consent to all actions we take with respect to your information consistent with our privacy policy.
If you choose, or are provided with, a username, password or any other piece of information as part of our security procedures, you must treat such information as confidential, and you must not disclose it to any other person or entity. You also acknowledge that your account is personal to you and agree not to provide any other person with access to this website or portions of it using your user name, password or other security information. You agree to notify us immediately of any unauthorized access to or use of your user name or password or any other breach of security. You also agree to ensure that you exit from your account at the end of each session. You are responsible for using particular caution when accessing your account from a public or shared computer so that others are not able to view or record your password or other personal information.

Intellectual property rights

The website and its entire contents, features and functionality (including but not limited to all information, software, text, displays, images, video and audio, and the design, selection and arrangement thereof), are owned by Bold Developer, its licensors or other providers of such material and are protected by United Arab Emirates and international copyright, trademark, patent, trade secret and other intellectual property or proprietary rights laws.

These terms of use permit you to use the website for your personal, non-commercial use only. You must not reproduce, distribute, modify, create derivative works of, publicly display, publicly perform, republish, download, store or transmit any of the material on our website, except as follows:

• Your computer may temporarily store copies of such materials in ram incidental to your accessing and viewing those materials.
• You may store files that are automatically cached by your web browser for display enhancement purposes.
• You may print or download one copy of a reasonable number of pages of the website for your own personal, non-commercial use and not for further reproduction, publication or distribution.
• If we provide desktop, mobile or other applications for download, you may download a single copy to your computer or mobile device solely for your own personal, non-commercial use, provided you agree to be bound by our end user license agreement for such applications.
• If we provide social media features with certain content, you may take such actions as are enabled by such features.

You must not:

• Modify copies of any materials from this site.
• Republish any part of the website on another website, in any other medium (print, electronic or otherwise) or as part of any commercial service.
• Use any illustrations, photographs, video or audio sequences or any graphics separately from the accompanying text.
• Delete or alter any copyright, trademark or other proprietary rights notices from copies of materials from this site.

No right, title or interest in or to the website or any content on the site is transferred to you, and all rights not expressly granted are reserved by Bold Developer. Any use of the website not expressly permitted by these terms of use is a breach of these terms of use and may violate copyright, trademark and other applicable laws.

Trademarks

Bold Developer’s names, brand names, Bold Developer’s logos and all related names, logos, product and service names, designs and slogans are trademarks of Bold Developer or its affiliates or licensors. You must not use such marks without the prior written permission of Bold Developer. All other names, logos, product and service names, designs and slogans on this website are the trademarks of their respective owners.

Prohibited uses

You may use the website only for lawful purposes and in accordance with these terms of use. You agree not to use the website:

• In any way that violates any applicable federal, local or international law or regulation, including without limitation, any form of misuse of credit cards or other forms of electronic payments.
• To transmit, or procure the sending of, any advertising or promotional material, including any “junk mail”, “chain letter” or “spam” or any other similar solicitation.
• To impersonate or attempt to impersonate a Bold Developer, a Bold Developer employee, another user or any other person or entity (including, without limitation, by using e-mail addresses or screen names associated with any of the foregoing).
• To engage in any other conduct that restricts or inhibits anyone’s use or enjoyment of the website, or which, as determined by us, may harm Bold Developer or users of the website or expose them to liability.

Moreover, you agree not to:

• Use any robot, spider or other automatic device, process or means to access the website for any purpose, including monitoring or copying any of the material on the website.
• Use any manual process to monitor or copy any of the material on the website or for any other unauthorized purpose without our prior written consent.
• Use any device, software or routine that interferes with the proper working of the website.
Introduce any viruses, trojan horses, worms, logic bombs or other material which is malicious or technologically harmful.
• Attempt to gain unauthorized access to, interfere with, damage or disrupt any parts of the website, the server on which the website is stored, or any server, computer or database connected to the website.
• Attack the website via a denial-of-service attack or a distributed denial-of-service attack.
Otherwise attempt to interfere with the proper working of the website.

Reliance on information

The information presented on or through the website about “The Collective” is made available solely for general information purposes. We do not warrant the accuracy, completeness or usefulness of this information. Any reliance you place on such information is strictly at your own risk. We disclaim all liability and responsibility arising from any reliance placed on such materials by you or any other visitor to the website, or by anyone who may be informed of any of its contents. Bold Developer are not liable for any errors, omissions, or inaccuracies in any information or documents provided on the website.
Bold Developer reserves the absolute right, without any liability whatsoever, to amend, vary or extend at any time the completion date of its projects inter alia the estimated/scheduled completion date(s) mentioned on or through the website.

Update of the website

We may update the content on the website from time to time, but its content is not necessarily complete or up-to-date. Any of the material on the website may be out of date at any given time, and we are under no obligation to update such material.

Subtitle: Information about you and your visits to the website

All information we collect on this website is subject to our privacy policy. By using the website, you consent to all actions taken by us with respect to your information in compliance with the privacy policy.

Terms of advertisements outside the united arab emirates

All purchases shall be in United Arab Emirates Dirhams (aed), regardless of whether the corresponding advertisements are in other currencies. Please note that, due to currency fluctuations the amounts listed on Bold Developer’s advertisements in currencies other than aed may be lower or higher at the time of signing or reviewing of any relevant document, offering or correspondence.

We recommend contacting a Bold Developer sales centre to obtain written confirmation of the purchase price in aed. It shall be your responsibility to obtain and retain this written evidence.

All purchases and/ or other transactions shall be subject to signing a separate document(s) with its own terms and conditions. The amount stated otherwise, in writing, by Bold Developer at their exclusive discretion.

Linking to the website and social media features

You may link to any page, provided you do so in a way that is fair and legal and does not damage our reputation or take advantage of it, but you must not establish a link in such a way as to suggest any form of association, approval or endorsement on our part. You accept that any reputational or other damage caused by such linking shall be determined by Bold Developer at its sole and exclusive discretion.

This website may provide certain social media features that enable you to:

• Link from your own or certain third-party websites to certain content on this website.
• Send e-mails or other communications with certain content, or links to certain content, on this website.
• Cause limited portions of content on this website to be displayed or appear to be displayed on your own or certain third-party websites.

You may use these features solely as they are provided by us, solely with respect to the content they are displayed with and otherwise in accordance with any additional terms and conditions we provide with respect to such features.

Subject to the foregoing, you must not:

• Establish a link from any website that is not owned by you.
• Otherwise take any action with respect to the materials on this website that is inconsistent with any other provision of these terms of use.

You agree to cooperate with us in causing any unauthorized framing or linking immediately to cease. We reserve the right to withdraw linking permission without notice.

We may disable all or any social media features and any links at any time without notice in our discretion.

Links from the website

If the website contains links to other sites and resources provided by third parties, these links are provided for your convenience only. This includes links contained in advertisements, including banner advertisements and sponsored links. We have no control over the contents of those sites or resources, and accept no responsibility for them or for any loss or damage that may arise from your use of them. If you decide to access any of the third party websites linked to this website, you do so entirely at your own risk and subject to the terms and conditions of use for such websites and Bold Developer accepts no responsibility and shall not be liable, in any way, for any consequences arising either directly or indirectly from your accessing such links.

Geographic restrictions

The owner of the website is based in the United Arab Emirates. We make no claims that the website or any of its content is accessible or appropriate outside of the United Arab Emirates. Access to the website may not be legal by certain persons or in certain countries. If you access the website from outside the United Arab Emirates, you do so on your own initiative and are responsible for compliance with local (or applicable) laws.

Disclaimer of warranties

You understand that we cannot and do not guarantee or warrant that the website will be free of viruses or other destructive code. You are solely responsible for implementing sufficient procedures and checkpoints to satisfy your particular requirements for anti-virus protection and accuracy of data input and output, and for maintaining a means external to our website for any reconstruction of any lost data.

We will not be liable for any loss or damage caused by a distributed denial-of-service attack, viruses or other technologically harmful material that may infect your computer equipment, computer programs, data or other proprietary material (directly or indirectly) due to your use of the website or any services or items obtained through the website or to your downloading of any material posted on it, or from accessing any website (or materials) linked to it.

Your use of the website, its content and any services or items obtained through the website is at your own risk. The website, its content and any services or items obtained through the website are provided on an “as is” and “as available” basis, without any warranties of any kind, either express or implied. Neither Bold Developer nor any person associated with Bold Developer makes any warranty or representation with respect to the completeness, security, reliability, quality, accuracy or availability of the website or its contents. Without limiting the foregoing, neither Bold Developer nor anyone associated with Bold Developer represents or warrants that the website, its content or any services or items obtained through the website will be accurate, reliable, error-free or uninterrupted, that defects will be corrected, that our site or the server that makes it available are free of viruses or other harmful components or that the website or any services will otherwise meet your needs or expectations.

Bold Developer hereby disclaims all warranties of any kind, whether express or implied, statutory or otherwise, including but not limited to any warranties of non-infringement. The foregoing does not affect any warranties which cannot be excluded or limited under applicable law.

Limitation on liability

To the fullest extent permitted by applicable law, in no event will Bold Developer, its affiliates or their licensors, service providers, employees, agents, officers or directors be liable for any direct, indirect, incidental, consequential, or punitive loss or damages of any kind, under any legal theory, arising out of or in connection with your use, or inability to use, the website, any websites linked to it, any content on the website or such other websites or any services or items obtained through the website or such other websites, including any direct, indirect, special, incidental, consequential or punitive damages, including but not limited to, personal injury, pain and suffering, emotional distress, loss of revenue, loss of profits, loss of business or anticipated savings, loss of use, loss of goodwill, loss of data, and whether caused by tort (including negligence), breach of contract or otherwise, even if foreseeable. The foregoing does not affect any liability which cannot be excluded or limited under applicable law.

Indemnification

You agree to defend, indemnify and hold harmless Bold Developer, its affiliates, licensors and service providers, and its and their respective officers, directors, employees, contractors, agents, licensors, suppliers, successors and assigns from and against any claims, liabilities, damages, judgments, awards, losses, costs, expenses or fees (including all legal fees) arising out of or relating to your violation of these terms of use or your use of the website and, any use of the website’s content, services and products or your use of any information obtained from the website regardless of whether they are permitted by this terms of use.

Governing law and jurisdiction

All matters relating to the website and these terms of use and any dispute or claim arising therefrom or related thereto (in each case, including non-contractual disputes or claims), shall be governed by and construed in accordance with the laws in force in the Emirate of Dubai, United Arab Emirates without giving effect to any choice or conflict of law provision or rule (whether of the United Arab Emirates or any other jurisdiction). Any legal suit, action or proceeding arising out of, or related to, these terms of use or the website shall be instituted exclusively in the courts of Dubai, United Arab Emirates although we retain the right to bring any suit, action or proceeding against you for breach of these terms of use in your place or country of residence or any other relevant country. You waive any and all objections to the exercise of jurisdiction over you by such courts and to venue in such courts.

Limitation on time to file claims

Any cause of action or claim you may have arising out of or relating to these terms of use or the website must be commenced within one (1) year after the cause of action accrues, otherwise, such cause of action or claim is permanently barred.

Subtitle: Waiver and severability

No waiver by Bold Developer of any term or condition set forth in these terms of use shall be deemed a further or continuing waiver of such term or condition or a waiver of any other term or condition, and any failure of Bold Developer to assert a right or provision under these terms of use shall not constitute a waiver of such right or provision.

If any provision of these terms of use is held by a court or other tribunal of competent jurisdiction to be invalid, illegal or unenforceable for any reason, such provision shall be eliminated or limited to the minimum extent such that the remaining provisions of the terms of use will continue in full force and effect.

Entire agreement

The terms of use, our privacy policy and any document(s) (if applicable) shall constitute the sole and entire agreement between you and Bold Developer with respect to the website and supersede all prior and contemporaneous understandings, agreements, representations and warranties, both written and oral, with respect to the website or Bold Developer as a whole.

Your comments and concerns

This website is operated and owned by Bold Developer.

In respect of requests for technical support and other communications relating to the website, you can contact us by using our website contact form, or by emailing us at [email protected]

You understand and accept that by using this website in updating, changing or altering your personal information, address(es) or contact details, you are accepting that Bold Developer or any of its affiliates may, at their discretion, use such information as an alternative information to send legal notices under these terms of use, privacy policy or any relevant document(s). It is your obligation to immediately inform Bold Developer of any changes to such information.

Last updated: November 5, 2025